HIGH COURT OF JAMMU & KASHMIR AND LADAKH AT JAMMU Arb P No. 6/2025 Date of pronouncement : 20.02.2026 Date of Uploading : 23.02.2026 Shekhar Enterprises Engineer & Builder Contractor, Congress Bazaar Pathankot through its Partner Chander Shekhar Sharma, S/o Sh. Subash Chander Sharma, R/o H. No. 2294, Sector-18, Abrol Nagar, Pathankot-145001, Punjab. .....Petitioner(s) Through :- Mr. G S Thakur, Advocate v/s 1. University of Jammu, through its Vice Chancellor, B R Ambedkar Road, Jammu. 2. Registrar, University of Jammu, B R Ambedkar Road, Jammu. 3. Executive Engineer, University of Jammu, Works Department, B R Ambedkar Road, Jammu. .....Respondent(s) Through :- Mr. Manik Bhardawaj, Advocate CORAM: HON’BLE MR. JUSTICE SANJEEV KUMAR, JUDGE ORDER (ORAL) 1. The petitioner was allotted contract work for the construction of a Boys Hostel Civil and Sanitary work at Kathua Campus of Jammu University, pursuant to an agreement dated 29.01.2013 executed between the petitioner and Respondent No. 3/Executive Engineer of Respondent No. 1. 2. The petitioner has contended that there was a delay in execution of the work owing to one reason or another. However, in terms of letter dated Sr. No. 03 Arb P No. 6/2025 2 19.05.2014 issued by the Assistant Executive Engineer, it was confirmed that the work actually commenced on 04.11.2013 after the site was made available to the contractor. It is further stated that the petitioner completed the work and raised the claims amounting to Rs. 43,31,861/- including the earnest money and 10% reserve on work done, however, the said payment was not released. It is also stated that the petitioner is entitled to claim an amount of Rs. 2.605 Cr. Along with interest @ 18%. 3. The petitioner claims to have made various representations to the respondents, seeking release of the payment or, in the alternative, referral of the dispute to the arbitrator, but to no avail. The petitioner has placed on record a communication dated 21.10.2024 requesting settlement of the dispute or in the alternative treat the same as a notice invoking arbitration in terms of condition No. 26 of General Conditions of Contract forming part of the contract agreement. On the basis of these facts, the petitioner has sought appointment of an arbitrator to adjudicate the dispute arising out of the NIT No. UWD/12-13/4009-20 dated 23.01.2013. 4. The respondents have filed their response stating therein that the petitioner was required to complete the contract work within a period of twelve months as per the terms and conditions of the contract agreement, but inordinate delay was caused by the petitioner itself in execution of the work. It is further stated that the contract provides that any dispute, doubt, difference, or question of any kind, except certain matters, shall be referred to the Vice Chancellor, who has to act as an Arbitrator. The Arb P No. 6/2025 3 respondents have denied that they are under any obligation to pay the amount claimed by the petitioner. 5. Heard learned counsel for the parties and perused the record. 6. The existence of the arbitration agreement is not disputed by the respondents. In view of the admitted existence of an arbitration agreement and the failure of the respondents to refer the dispute to arbitration despite due notice, this Court finds that the pre-conditions for invocation of jurisdiction under Section 11 (6) of the Arbitration and Conciliation Act, 1996 stand satisfied. Although it is the stand of the respondents that Vice Chancellor has to act as an Arbitrator, the learned counsel for the respondents has fairly conceded that the said course is impermissible due to subsequent amendment. 7. It is well settled that where a named Arbitrator becomes ineligible or is unable to act, an independent and impartial Arbitrator can be appointed to ensure adjudication of the disputes between the parties. The disputes raised by the petitioner arise out of the execution of the contract and are arbitrable in nature. Accordingly, Sh. S. R. Gandhi, Retired District Judge is hereby appointed as the Sole Arbitrator to adjudicate the disputes between the parties arising out of NIT No. UWD/12-13/4009-20 dated 23.01.2013 and the agreement dated 29.01.2013. 8. The learned Arbitrator shall enter upon the reference after furnishing the disclosure as required under Section 12 (1) of the Arbitration and Conciliation Act, 1996 and shall conduct the arbitral proceedings in accordance with the provisions of the Act. The fee of the learned Arb P No. 6/2025 4 Arbitrator shall be governed by the Fourth Schedule of the Act, unless otherwise agreed between the parties. 9. The Registry shall send a copy of this order to the learned Arbitrator forthwith. 10. The petition stands disposed of in the above terms. (Sanjeev Kumar) Judge JAMMU 20.02.2026 Manan Whether the order is speaking : Yes/No Whether the order is reportable : Yes/No